SAWS Delays
Category: Other
Updated: 11 hours ago
Contributors
Created byJohn Depalma
Attachments
Events
From: Travis Farris <tfarris@mgccontractors.com>
Sent: March 9, 2023 10:54 AM
To: Doug Van der Veen <dvanderveen@amprocessgroup.com>
Subject: Re: Subcontract for Clouse WRC Clarifiers
Doug
I have submitted proposed sequencing to SAWS, which differs from what is spec’d. As soon as I have an answer, I will let you know.
Looks like a May/June timeframe to start but I’ll have to get a confirmation through the sequencing submittal.
Thank you
Travis Farris
Project Manager
tfarris@mgccontractors.com
210-694Specs: The anticipated notice to proceed (NTP) for this Project is April 26, 2022.
Respondent shall use this date for developing the proposed project schedule.John
We are on schedule to start cleaning the first set of digesters February 8, 2024.
Please advise that this time works for APG.
Thank you
Travis Farris
Project Manager
tfarris@mgccontractors.com
210-694-0565 (TX Office)
830-931-1699 (Cell)
www.mgccontractors.comJohn,
We are notifying SAWS that we would like to schedule the first two sets of digesters to begin draining on 2/26/2024.
We would like to get APG on the books for the first week of March 2024 to begin mobilizing.
Do you recommend having a on site meeting or Teams meeting to discuss logistics of APGs scope?
If you have any questions, please feel free to contact me.
Best,
Hugo Guillen
Project Engineer
Mobile 210-717-6424
Texas Office 210-694-0565
www.mgccontractors.comStart cleaning digesters 5 and 7John,
Our most updated schedule shows us starting to clean the Digesters beginning of May.
Hoping everything stays on track for our start up of DIG 5 and 7 we should be holding these dates.
If anything changes I will reach out ASAP.
Hugo Guillen
Project Engineer
Mobile 210-717-6424
Texas Office 210-694-0565
www.mgccontractors.comJohn,
After the schedule update we did this morning,
we are expected to be ready for APG to be on site ready to start cleaning June 4th.
Please contact Omar or myself to schedule when you would like to start sending equipment back on site.
Thanks,
Hugo Guillen
Project Engineer
Mobile 210-717-6424
Texas Office 210-694-0565
www.mgccontractors.comHi John,
Following up on our phone conversation yesterday,
I’d like to confirm that the start date for APG’s draining operations will need to be postponed. The new scheduled start date is July 7th.
This delay is due to unforeseen issues with existing equipment at the Steven M. Clouse facility, which fall outside the scope of our work.
These equipment failures have impacted the completion of critical testing required to turn over DIG 5 and 7.
As a result, we are unable to take DIG 6 and 8 offline and bePossible delay until early to mid AugustSchedule received via email from Travis Harris on Tuesday, May 2, 2023
Comments